From Casetext: Smarter Legal Research

Raabe v. Squier

Court of Appeals of the State of New York
Dec 19, 1895
42 N.E. 516 (N.Y. 1895)

Summary

In Raabe v. Squier (148 N.Y. 81) the plaintiff, as subcontractor, agreed to deliver to the principal contractor for the erection of a building, certain materials.

Summary of this case from Voska, Foelsch Sidlo, Inc. v. Ruland

Opinion

Argued December 11, 1895

Decided December 19, 1895

Herman Aaron for appellants. Ernest Hall for respondents.


This action was brought to recover the sum of $2,800, the balance claimed to be due on contracts between the defendants Squier and Whipple and the plaintiffs, in which the plaintiffs undertook to furnish the woodwork for ten houses which the defendants Squier and Whipple were building on West End avenue in the city of New York, which were owned by the defendants Jencks and Stokes.

The complaint alleges that the defendants Jencks and Stokes "promised and agreed with the plaintiffs to be answerable to the said plaintiffs for the payments to be made under the contracts aforesaid, and guaranteed the payments therein mentioned in consideration of the plaintiffs fulfilling and completing the contracts aforesaid, and promised and agreed to pay the plaintiffs for all the work, labor and services and material furnished under the aforesaid contracts if the said Squier and Whipple would not pay."

The complaint also alleged the filing of a mechanic's lien by the plaintiffs, and concluded by demanding judgment for the foreclosure thereof, and also a judgment against the defendants Squier and Whipple for the balance due under their contracts, and against the defendants Jencks and Stokes for such balance under their promise to pay, in case of the default of Squier and Whipple.

The case was tried before a referee, who, at the conclusion of the plaintiff's testimony, on motion of the defendants, dismissed the plaintiff's complaint, to which ruling the plaintiffs took an exception. Fifteen days thereafter the referee made and filed a report on which the judgment appealed from was entered.

It is contended on behalf of the defendants that there is no question which the plaintiffs can have reviewed; that the plaintiffs having neglected to make requests to find facts, it is now the duty of the court to assume that there was sufficient evidence to sustain the judgment. But the plaintiffs may take exceptions to the findings as made, and if there is not any evidence tending to sustain them, they may be regarded as rulings upon questions of law. (Code C.P. § 993.) The plaintiffs have not only taken exceptions to the findings of fact and conclusions of law, but as we have seen have also taken an exception to the order of the referee dismissing their complaint. It is also contended that the report of the referee contained negative findings of fact; that such findings are unauthorized and should be treated as a nullity, and that exceptions taken to such findings are of no avail upon review. If the report is to be treated as a nullity, there is nothing upon which the judgment can stand, for there must be a report. (Code C.P. sec. 1022.) If there be no report the party aggrieved may be relieved under section 1010 of the Code. ( Gilman v. Prentice, 132 N.Y. 488, 491.)

The action of the referee was, in effect, a non-suit, and, we think, the exceptions taken present questions for review. In Place v. Hayward ( 117 N.Y. 487) the trial was before a referee. At the close of the plaintiff's evidence the defendant, without announcing that he rested his case, moved that the complaint be dismissed. The referee granted the motion and the plaintiff excepted. Thereafter the referee made his report containing findings of fact and a conclusion of law that the complaint should be dismissed. The practice adopted in that case was the same as that which we now have under review. In that case Judge EARL, in delivering the opinion of the court, said: "What the referee did was to non-suit the plaintiff. We can give no other significance to the proceeding. Therefore, he should have made no findings of fact except such as would justify a non-suit upon the trial. Under the Code the referee was required to make findings of fact and of law after granting the non-suit; but he had no right to make any findings of fact depending upon disputed or inconclusive evidence. Therefore, to maintain this judgment, the defendant is bound to show that there was no disputed question of fact which, upon a jury trial, the court would have been required to submit to the jury, and that upon the undisputed evidence he was entitled to judgment." Citing Scofield v. Hernandez ( 47 N.Y. 313). In Forbes v. Chichester ( 125 N.Y. 769) the same practice was adopted on the trial. The judgment was reversed in this court, upon the exception taken to the dismissal of the complaint, upon the ground that the trial court erred in holding as matter of law that, upon the evidence adduced, the plaintiff failed to establish a cause of action. The case of Wood v. Lary ( 124 N.Y. 83) is not in conflict with the cases above referred to. In that case the referee had filed no report whatever, and it was then held that section 1010 of the Code afforded the plaintiff ample protection.

In so far as the action was prosecuted to establish a mechanic's lien it cannot be sustained. While the complaint contains some allusions to a contract between Jenks and Stokes as owners, and Squier and Whipple as builders, it contains no distinct allegation that there was such a contract, nor is there any evidence that there was any sum remaining unpaid by the owners thereon. But upon the contract with Squier and Whipple and the promise of Jencks and Stokes it appears to us that the evidence was sufficient to establish the plaintiffs' claim, and that their complaint should not have been dismissed.

The referee finds that Jencks and Stokes were not the owners of the premises upon which the buildings were being constructed. It is alleged in the complaint that they were such owners, and Stokes, in his answer, admits that he was the owner of the southerly half of the premises, and it appears from the testimony that Jencks and Stokes repeatedly asserted that they were the owners, and that they were building the houses thereon together as co-partners. This evidence is not in any manner controverted. The admission of a party is evidence against him, and in so far as it affects his liability he is bound by it unless he can show that it was not made, intended or correctly understood.

The facts then as disclosed by the evidence are substantially as follows: Jencks and Stokes were the owners of the premises. Squier and Whipple were building the houses thereon for them. Squier and Whipple entered into a contract with the plaintiffs to furnish the woodwork for the houses for the sum of $20,000. The payments were to be made in installments in cash, less ten per cent discount, on the the delivery of the material at the buildings. The contract specifically designated the material to be delivered upon each installment. The plaintiffs prepared the first installment of material, and delivered the same at the buildings, and then called upon the defendants, Squier and Whipple, for the first payment due them under the contract, but the same was delayed and not made for the space of about three months. The plaintiffs prepared and delivered the second installment of material, and also demanded payment for that, which was neglected and delayed. The plaintiffs then prepared the rest of the material called for by the contract, but refused to deliver the same until the installments furnished by them had been paid for. Under these circumstances the defendants Jencks and Stokes saw the plaintiffs and told them that they were the owners of the buildings; that they wanted them finished and that if the plaintiffs would go ahead and deliver the rest of the material they would see them paid therefor; that if Squier and Whipple did not pay they would take it out of the amount going to them and would pay the plaintiffs. It further appears that, relying upon this promise, the plaintiffs proceeded and delivered all the material called for by the contracts, but that the sum of $2,800 still remains due to them and unpaid.

The referee dismissed the complaint as to Jencks and Stokes upon the ground, as he says, that their promise to pay being oral was void under the Statute of Frauds and as to Squier and Whipple upon the ground that "before the delivery of any goods by the plaintiffs under the terms of the contract the plaintiffs refused to carry out or fulfill said contract on their part with the defendants Squier and Whipple."

Considering the last proposition first, we are at a loss to understand upon what evidence it is founded. It is true that the last batch of material was not delivered until December, but we are told that the delay in delivering was because of the non-payment of the amount due on former deliveries. The refusing to deliver an installment until a former installment had been paid for was not a breach of the contract on the part of the plaintiffs. As to the Statute of Frauds it appears to us that its provisions have no application to the case under consideration. In the first place the indebtedness at the time the promise was made has been paid. The promise, in so far as it is here sought to be enforced, related to the indebtedness thereafter to be created. The promisors were the owners of the buildings in process of construction. The woodwork furnished by the plaintiffs was for their benefit. The contractors had neglected to pay the plaintiffs for the material furnished and they refused to deliver more, as they had the right to do. Under such circumstances the promise was made, and it was in reliance upon the promise that the plaintiffs delivered the rest of the woodwork. The promise thus made was original and founded upon a new consideration, that of the goods. It was beneficial, as we have seen, to the promisors, thus bringing the case within the rule stated by FINCH, J., in White v. Rintoul ( 108 N.Y. 222, 227), in which he says: "Where the primary debt subsists and was antecedently contracted, the promise to pay it is original when it is founded on a new consideration moving to the promisor and beneficial to him, and such that the promisor thereby comes under an independent duty of payment irrespective of the liability of the principal debtor." ( Ackley v. Parmenter, 98 N.Y. 425; Prime v. Koehler, 77 N.Y. 91; Bayles v. Wallace, 56 Hun, 428.)

The judgment should be reversed and a new trial granted, costs to abide the event.

All concur.

Judgment reversed.


Summaries of

Raabe v. Squier

Court of Appeals of the State of New York
Dec 19, 1895
42 N.E. 516 (N.Y. 1895)

In Raabe v. Squier (148 N.Y. 81) the plaintiff, as subcontractor, agreed to deliver to the principal contractor for the erection of a building, certain materials.

Summary of this case from Voska, Foelsch Sidlo, Inc. v. Ruland

In Raabe v. Squier (supra) it was held that an agreement, by a party interested in having another perform a contract, to guarantee payment, and to pay if the party to whom materials were to be furnished and delivered "would not," was not within the statute.

Summary of this case from R. L. Co. v. Metz

In Raabe v. Squier (supra) the plaintiffs had entered into an agreement with contractors to furnish materials to be used in the erection of buildings on the premises of defendants. Two installments of these materials had been delivered, but the contractors had neglected to make payment as stipulated in the agreement.

Summary of this case from Almond v. Hart
Case details for

Raabe v. Squier

Case Details

Full title:HENRY RAABE et al., Appellants, v . ALBERT C. SQUIER et al., Respondents

Court:Court of Appeals of the State of New York

Date published: Dec 19, 1895

Citations

42 N.E. 516 (N.Y. 1895)
42 N.E. 516

Citing Cases

Sunshine v. Furtick

nstrue thewritten contract which was plain and unambiguous: 17 S.C. 479; 22 S.C. 288; 24 S.C. 497; 103 S.C.…

Schwoerer Sons, Incorporated v. Stone

It is fairly to be inferred from Schwoerer's testimony that the defendant not only was interested in the…